Fairfield Connecticut Building Expert Directory

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Construction Law Firm Opens in D.C.

January 13, 2014 — CDJ STAFF
Stephen Palley, a lawyer in the Washington, D.C. area who was recognized in 2013 as a “DC Super Lawyer” for his work in construction litigation, has open his own firm, Palley Law, PLLC. Mr. Palley said that his practice “remains focused on addressing insurance issues faced by construction industry clients.” He also noted that “few firms focus specifically on construction insurance, so a significant part of my practice involves helping other lawyers with individual projects or disputes for their clients.” Read the court decision
Read the full story...
Reprinted courtesy of

UPDATE: Texas Federal Court Permanently Enjoins U.S. Department of Labor “Persuader Rule” Requiring Law Firms and Other Consultants to Disclose Work Performed for Employers on Union Organization Efforts

December 08, 2016 — Aaron C. Schlesinger & Gregory R. Begg – Peckar & Abramson, P.C.
As an update to our prior alert, on November 16, 2016, a federal judge in Texas issued a permanent injunction blocking the U.S. Department of Labor’s (“DOL”) “persuader rule” – a preliminary injunction had been granted this past June. In rendering the permanent injunction, the court adopted the reasoning of its prior June 27, 2016 decision that granted a nationwide preliminary injunction on the rule. In the earlier decision, the court held that a temporary injunction was appropriate because the parties challenging the rule were likely to succeed on the merits of their claim […]. Reprinted courtesy of Aaron C. Schlesinger, Peckar & Abramson, P.C. and Gregory R. Begg, Peckar & Abramson, P.C. Mr. Schlesinger may be contacted at aschlesinger@pecklaw.com Mr. Begg may be contacted at gbegg@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Traub Lieberman Attorneys Recognized as 2020 Super Lawyers and Rising Stars

November 16, 2020 — Traub Lieberman
Traub Lieberman is pleased to announce that Super Lawyers has named nineteen of our attorneys as 2020 Super Lawyers and Rising Stars. Super Lawyers selects attorneys using a multiphase selection process in which nominations and evaluations are combined with independent research. Each candidate is evaluated on 12 indicators of peer recognition and professional achievement. Selections are made on an annual, state-by-state basis. The objective is to create a credible, comprehensive and diverse listing of outstanding attorneys that can be used as a resource for attorneys and consumers searching for legal counsel. The Super Lawyers designation recognizes the top 5% of attorneys in the U.S. and the Rising Stars designation recognizes the top 2.5% of attorneys in the U.S. under the age of forty, as chosen by their peers and through independent research within their practice area. Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman

Number of Occurrences Is On the Agenda at This Year's ICLC Seminar

February 05, 2015 — Tred R. Eyerly – Insurance Law Hawaii
This year's Insurance Coverage Litigation Committee's CLE Seminar will be conducted in Tucson, Arizona, from March 4-7, 2015. Each year, the conference offers informative, cutting-edge sessions on a variety of insurance-related topics. Participants from across the country with varying perspectives on insurance coverage, including lawyers, judges, risk managers, and insurance professionals, will be attendance. The seminar's brochure is attached here. "Number of Occurrences" will be the topic my panel presents on March 7. We will be honored to have on our panel Alaska Supreme Court Justice Peter Maassen, my old skiing and running buddy from my Alaska days. Justice Maassen's opinion in United Servs. Auto. Ass'n. v. Neary, 307 P.3d 907 (Alaska 2013) was the genesis for our topic. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

What is the True Value of Rooftop Solar Panels?

April 15, 2014 — Beverley BevenFlorez-CDJ STAFF
In Colorado, regulators are questioning the true value of rooftop solar panels, reported the Denver Business Journal: “Minneapolis-based Xcel Energy Inc. (NYSE: XEL), the biggest utility in Colorado, has said it believes Colorado’s current ‘net metering’ policy means the utility is overpaying customers who have rooftop solar power systems.” Currently, “Xcel...credits customers at a rate of 10.5 cents per kilowatt hour of excess power produced.” However, the utility company believes that “the ‘true value’ of the rooftop solar electricity is about half what it’s paying—just 4.6 cents per kilowatt hour.” According to the Denver Business Journal, supporters argue that “Xcel has undervalued the electricity and hasn’t accounted for the systems’ environmental and economic attributes.” Read the court decision
Read the full story...
Reprinted courtesy of

Nevada Supreme Court Reverses Decision against Grader in Drainage Case

June 30, 2011 — CDJ STAFF

The Nevada Supreme Court has issued an opinion in the case of Rayburn Lawn & Landscape Designers v. Plaster Development Corporation, reversing the decision of the lower court and remanding the case for a new trial.

The case originated in a construction defect suit in which Plaster Development Corporation was sued by homeowners. Plaster filed a third-party complaint against its subcontractor, Reyburn. The testimony of Reyburn’s owner was considered to be admission of liability and so the court limited the scope of Reyburn’s closing argument and did not allow the jury to determine the extent of Reyburn’s liability. Reyburn appealed.

Plaster, in their case, cited California’s Crawford v. Weather Sheild MFG, Inc. The court held the application of these standards, but noted that the “an indemnitor’s duty to defend an indemnitee is limited to those claims directly attributed to the indemnitor’s scope of work and does not include defending against claims arising from the negligence of other subcontractors and the indemnittee’s own negligence.”

On the matter of law against Reyburn, the court concluded, “Given the conflicting evidence at trial as to whether Reyburn’s work was implicated in the defective retaining walls and sidewalls, and viewing the evidence and inferences in Reyburn’s favor, we conclude that a reasonable jury could have granted relief in favor of Reyburn.” The Nevada Supreme Court conduced that the district court should not have granted Plaster’s motion for judgement.

Further, the Nevada Supreme Court found that the district court should have apportioned the fees and costs to those claims directly attributed to Reyburn’s scope of work, “if any,” and should not have assigned all attorney costs and court fees to Reyburn.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

Predicting Our Future with Andrew Weinreich

May 03, 2017 — Aarni Heiskanen - AEC Business
In this podcast episode, my guest is Andrew Weinreich. We talk about the future of homebuilding against the backdrop of Andrew’s new podcast Predicting Our Future. Is construction ripe for disruption? Andrew believes that homebuilding is much closer to a tipping point than ever before. In this interview, he explains why. “In the United States, modular construction significantly lags behind what we see elsewhere around the world,” Andrew reminds. “When everything you can imagine today, from the paperclip to your smartphone is made in a factory, why is it that -certainly in this country- we associate homes made in factory with the lowest of low end homes.” “The first question is: why is that? And the second question is: could that change? Could we be on the precipice of looking at the next Tesla; not for car-building, but for homebuilding.” Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at info@aepartners.fi

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES