FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

William Lyon Homes Unites with Polygon Northwest Company

June 26, 2014 — Beverley BevenFlorez-CDJ STAFF
Big Builder’s Les Shaver reported that William Lyon Homes has acquired Polygon Northwest Company, “the largest private home builder in the [Pacific Northwest] region,” for “approximately $520 million.” "Polygon Northwest Company brings an attractive level consistency to William Lyon Homes with a steady average of 57 homes per month and a portfolio of communities that includes a nice product mix of single family detached [80 percent] and attached product [20 percent]," Catherine LaFemina, director of business development in the Seattle market for Metrostudy, told Big Builder. "Based on the trailing 12 months of home closings, [June 2013 to May 2014], Lyon’s acquisition of Polygon will increase the volume of homes being delivered by 50 percent to an average monthly volume of about 115 homes per month." Read the court decision
Read the full story...
Reprinted courtesy of

---

Concrete Worker Wins Lawsuit and Settles with Other Defendant

December 04, 2013 — CDJ STAFF
Hildo De Franca was injured in 2010 while pouring concrete for a residence in Perkasie, Pennsylvania. According to the lawsuit, when a concrete line plugged, the truck operator increased pump pressure, despite this not being the appropriate procedure. Mr. De Franca was injured when the hose snapped back after the clog burst free. Mr. De Franca sued both the Trans-Fleet Concrete Inc. and Albino Concrete Construction. Mr. De Franca was employed by a third party, Girafa Construction Inc., which had been hired by Albino. Albino Construction settled with Mr. De Franca for $500,000. Trans-Fleet did not settle. The judgment against them was for $2.25 million, of which $2 million was for pain and suffering. As a result of the accident, Mr. De Franca suffered a mild brain injury and a compression fracture in his spine. Read the court decision
Read the full story...
Reprinted courtesy of

---

Rams Owner Stan Kroenke Debuts His $5.5 Billion Dream Stadium

September 14, 2020 — Christopher Palmeri - Bloomberg
The first thing you notice that’s different about SoFi Stadium is that you can walk from the parking lot almost directly into the fifth level of the arena. There’s no passing through gate after gate or ascending endless circular walkways. Construction workers dug up over 7 million cubic yards of dirt to build an arena that sits 100 feet (30 meters) below grade. It’s one of the many features that make SoFi, the National Football League’s biggest stadium, surprisingly visitor-friendly. Not that fans will be able to experience it just yet. When the stadium debuts Sunday with the first game of the Los Angeles Rams’ season, it will be spectator-free -- the result of pandemic-spurred restrictions on gatherings. But it will still be a spectacle. Read the court decision
Read the full story...
Reprinted courtesy of Christopher Palmeri, Bloomberg

---

Formaldehyde-Free Products for Homes

March 05, 2015 — Beverley BevenFlorez-CDJ STAFF
Builder Magazine reported that builders are “making indoor air quality a major concern,” including choosing healthier, formaldehyde-free products. Builder explained the problems with certain chemicals: “Formaldehyde and other VOCs, most frequently found in wood products, finishes, and paints, have been chief among the pollutants targeted for potentially dangerous health effects, such as respiratory issues and irritation of the eyes, nose, throat, and skin.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Pennsylvania Supreme Court Adopts New Rule in Breach-of-the-Consent-to-Settle-Clause Cases

August 19, 2015 — Sean Mahoney – White and Williams LLP
In Babcock & Wilcox Company, et al. v. America Nuclear Insurers, et al., the Pennsylvania Supreme Court recently held that where a liability insurer has agreed to provide a defense to its insured in an underlying tort action subject to a reservation of rights but refuses to consent to a settlement in that action, the insured may nevertheless accept the settlement over the insurer’s objection where the settlement is “fair, reasonable, and non-collusive” from the perspective of a reasonably prudent person in the insured’s position in light of the totality of the circumstances and is covered. Babcock & Wilcox Company v. America Nuclear Insurers, No. 2 WAP 2014, 2015 WL 4430352 (Pa. Jul. 21, 2015). This decision fills an important gap in Pennsylvania precedent addressing the rules applicable when an insurer refuses to consent to an insured’s settlement of a lawsuit. In Babcock, the underlying plaintiffs sued Babcock & Wilcox Company and Atlantic Richfield Company (“the Insureds”) alleging that the Insured’s nuclear facilities caused bodily injury and property damage. The Insureds’ liability insurers agreed to defend the Insureds subject to a reservation of rights. The insurers later refused to consent to an offer to settle the underlying action for a total of $80 million because they believed the Insureds were likely to succeed on the merits. Nevertheless, in 2009, the Insureds accepted that offer and settled the underlying action for $80 million, notwithstanding the insurer’s refusal. The Insureds then sought reimbursement of the $80 million settlement from their insurers, who rejected that request on the ground that the Insureds had breached the consent-to-settlement/cooperation provisions of the implicated policies. Read the court decision
Read the full story...
Reprinted courtesy of Sean Mahoney, White and Williams LLP
Mr. Mahoney may be contacted at mahoneys@whiteandwilliams.com

---

Mark Van Wonterghem To Serve as Senior Forensic Consultant in the Sacramento Offices of Bert L. Howe & Associates, Inc.

March 01, 2012 — CDJ STAFF

Sacramento, CA — Bert L. Howe and Associates, Inc., is pleased to announce that Mark Van Wonterghem - General Contractor, has joined the firm as Senior Forensic Consultant. Mark will be responsible for leading the firm’s expansion in the newly formed Sacramento headquarters.



His focus will continue to be working with construction practice groups and claims professionals in the Sacramento and Bay Area markets. He will utilize the resources of the Construction Experts Group at Bert L. Howe & Associates in furthering the litigation support needs attendant to the firm’s Northern California clientele.



Mr. Van Wonterghem possesses extensive consulting and testimony experience. Through 32 years of experience in the construction industry he leverages extensive practical experience with multiple trades including concrete foundations, walls and flatwork, structural wood and steel framing, finish carpentry, drywall, lath & plaster/stucco, window & door installations, deck coating systems, metal and membrane flashings and above/below grade waterproofing. This trade experience encompasses both the commercial and residential construction sectors and has been vital in his ability to provide concise explanation of construction industry standards, as well as trade-specific standards of care.



Mr. Van Wonterghem has broad experience with all types of building construction ranging from concrete and steel commercial construction to high-end custom residential construction.



In connection with the Construction Experts Group at BHA, Mr. Van Wonterghem provides construction consulting and litigation support services to a wide variety of recognized construction claims professionals, owners, and publicly traded builders.



The firm’s Sacramento offices are located at the Gateway Oaks III office complex, 2520 Venture Oaks Way, Suite 435, Sacramento, CA 95833. Mr. Van Wonterghem can be reached via e mail at mvanwonterghem@berthowe.com or at (800) 783-1822.

Read the court decision
Read the full story...
Reprinted courtesy of

---

Zillow Topping Realogy Shows Web Surge for Housing Market

July 30, 2014 — Prashant Gopal and John Gittelsohn – Bloomberg
Zillow Inc. (Z)’s purchase of Trulia Inc. makes the online company such a force in U.S. real estate that its market value now surpasses that of Realogy Corp., owner of renowned brokerage brands from Coldwell Banker to Century 21. Zillow, the biggest U.S. real estate website, has seen its market value jump to about $5.83 billion from $4.99 billion on July 23, the day before Bloomberg News reported the deal talks with rival Trulia. Realogy, the largest residential brokerage operator, has a market value of about $5.47 billion, compared with $5.67 billion last week, data compiled by Bloomberg show. The shift underscores the growing role of the Web in U.S. home sales as buyers start their hunt for homes and mortgages online and rely less on real estate agents, a migration that has taken longer than in industries such as music or travel. While Zillow is unlikely to compete directly with brokers, whose ad dollars are its top revenue source, buying Trulia (TRLA) gives it more command over marketing fees, sparking concerns among Realtors such as Stephen FitzMaurice that costs will rise. Mr. Gopal may be contacted at pgopal2@bloomberg.net; Mr. Gittelsohn may be contacted at johngitt@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal and John Gittelsohn, Bloomberg

---

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---