Underpowered AC Not a Construction Defect
November 07, 2012 —
CDJ STAFFAfter buying a home in Louisiana, Mike Gines determined that the home’s air conditioning unit was insufficient to maintain an appropriate temperature. He contacted the home builder, D.R. Horton, Inc., which worked with the air conditioning installer, Reliant Heating & Air Conditioning, in order to repair the system. When the problems persisted, Gines filed a class action petition against Horton and Reliant in state court. Horton and Reliant moved the case to the federal courts, whereupon Gines asserted the defendants were in violation of the Louisiana New Home Warranty Act (NHWA). Horton stated that the claim under the NHWA was invalid, because Gines had not alleged actual physical damage to his home.
The district court granted Horton’s motion to dismiss. Gines sought a reversal from the Fifth Circuit Court of Appeals and sought to have two questions of state law addressed by the Louisiana Supreme Court.
The district court ruled that the NHWA was the “sole remedy under Louisiana law for a purchaser of a new home with construction defects. Gines argued that court erred in this, but also conceded that this was the conclusion of the Louisiana Supreme Court.
Further, Gines argued that a provision in the NHWA that allows the inclusion of construction defects that do not cause damage was satisfied by paragraph 6 of the contract. The court noted that Gines did not attach a copy of the contract to either the original or amended complaint, and so the court does not need to address these claims. However, the court cautioned that if a copy had been included, they still would have rejected the claim, as “the cited language does not indicate a waiver of the physical damage requirement.” They also note that “paragraph 13 of the contract shows that Gines was aware to the absence of any such waiver in the contract.”
The court concludes that “the moral of this story is that in order to avoid the harsh result that has obtained here, the buyer of a newly constructed home in Louisiana should seek to obtain in the contract of sale an express waiver of the actual damage requirement of the NHWA.” The appeals court affirmed the decision of the circuit court and denied the application to certify questions to the Louisiana Supreme Court.
Read the court decisionRead the full story...Reprinted courtesy of
Architect Norman Foster Tells COP26: Change 'Traditional' City Design to Combat Climate Change
November 19, 2021 —
James Leggate - Engineering News-RecordRegaining control over the climate crisis will require a change in the way cities are designed and built, noted British architect Sir Norman Foster told global attendees at the
COP26 summit in Glasgow, Scotland, in a presentation with John Kerry, President Joe Biden's special climate envoy.
Reprinted courtesy of
James Leggate, Engineering News-Record
Mr. Leggate may be contacted at leggatej@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Tech Focus: Water Tech Getting Smarter
June 05, 2023 —
Pam McFarland - Engineering News-RecordIn early December 2021, the Denver International Airport made headlines across the U.S. after a hot water pipe broke a month before a major terminal expansion project was expected to complete. The scalding water spilled on floors and across the airport concourse, causing $50 million in damage and a nine-month delay to the project.
Reprinted courtesy of
Pam McFarland, Engineering News-Record
Ms. McFarland may be contacted at mcfarlandp@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Contractor’s Burden When It Comes to Delay
October 26, 2020 —
David Adelstein - Florida Construction Legal UpdatesWhen a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:
When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.
Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Is Performance Bond Liable for Delay Damages?
October 20, 2016 —
David Adelstein – Florida Construction Legal UpdatesThere is an argument that a performance bond is not liable for delay damages UNLESS the bond specifically allows for the recovery of such damages. Keep this in mind when requiring a performance bond so that the bond covers the associated risks (and damages) you contemplate when requiring the bond. This argument is supported by the Florida Supreme Court’s 1992 decision in American Home Assur. Co. v. Larkin General Hosp., Ltd., 593 So.2d 195, 198 (Fla. 1992):
The language in the performance bond, construed together with the purpose of the bond, clearly explains that the performance bond merely guaranteed the completion of the construction contract and nothing more. Upon default, the terms of the performance bond required American [performance bond surety] to step in and either complete construction or pay Larkin [obligee] the reasonable costs of completion. Because the terms of the performance bond control the liability of the surety, American’s liability will not be extended beyond the terms of the performance bond. Therefore, American cannot be held liable for delay damages.
However, the Eleventh Circuit in National Fire Ins. Co. of Hartford v. Fortune Const. Co., 320 F.3d 1260(11th Cir. 2003), also analyzing an issue relating to the recoverability of delay-type damages against a performance bond, did not narrowly interpret the Florida Supreme Court’s decision in Larkin General Hospital.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.Mr. Adelstein may be contacted at
dma@katzbarron.com
Nonparty Discovery in California Arbitration: How to Get What You Want
January 08, 2019 —
Leilani L. Jones - Payne & FearsOpting for arbitration requires attorneys to balance efficiency and procedural protections. The implications of arbitration are something clients certainly have to carefully consider both when drafting arbitration provisions, and after initiating a demand. While arbitration can in many respects streamline the civil discovery process, one of the largest roadblocks for cases in California arbitrations is “streamlining” discovery from nonparties. This article explores the challenges presented by third party discovery in arbitration, and proposes strategies for obtaining such discovery efficiently and expeditiously.
Read the court decisionRead the full story...Reprinted courtesy of
Leilani L. Jones, Payne & FearsMs. Jones may be contacted at
llj@paynefears.com
Gilbane Project Exec Completes His Mission Against the Odds
January 19, 2017 —
Debra K. Rubin - Engineering News-RecordAfghanistan’s new Ministry of Defense headquarters in Kabul was supposed to symbolize the nation’s future—and U.S. support in that effort—as a self-sustaining, sophisticated structure akin to the Pentagon. But U.S. funding shortfalls stretched an anticipated 18-month project, which began in 2009, into years. While experienced in running projects in an underdeveloped country in which terror attacks and unstable regional politics are routine, Gilbane Building Co. Project Executive Michael P. Sousa wanted no part of this one in 2013, when he first toured it. “The structure was in a severe state of disrepair and riddled with poor construction,” he says, terming it “an embarrassment” to the U.S. government.
Read the court decisionRead the full story...Reprinted courtesy of
Debra K. Rubin, ENRMs. Rubin may be contacted at
rubind@enr.com
In Pennsylvania, Contractors Can Be Liable to Third Parties for Obvious Defects in Completed Work
July 10, 2023 —
Michael L. DeBona - The Subrogation StrategistIn Brown v. City of Oil City, No. 6 WAP 2022, 2023 Pa. LEXIS 681 (2023), the Supreme Court of Pennsylvania (Supreme Court) recently held that a contractor can be liable for dangerous conditions it creates even if the hazard is obvious or known by the property owner. In City of Oil City, the City of Oil City (Oil City) contracted with Harold Best and Struxures, LLC and Fred Burns, Inc. (collectively Contractors) to reconstruct the concrete stairs to the city library. Contractors completed their work at the end of 2011. In early 2012, Oil City received reports of issues with the stairs. Oil City notified Contractors that it considered the stairs dangerous and that Contractors’ defective workmanship created the condition. Neither Oil City or Contractors took any action to fix the stairs or warn of the danger and the stairs’ condition worsened with time.
On November 23, 2015, David and Kathryn Brown exited the library. Kathryn Brown tripped on one of the deteriorated steps, falling and striking her head. Kathryn suffered a traumatic head injury and passed away six days later. The Estate of Kathryn Brown and David Brown, individually (collectively, the Browns), sued Oil City as the owner of the library and Contractors. With respect to Contractors, the Browns asserted that Contractors’ work on the stairs created a dangerous condition that presented an unreasonable risk of harm to those using the steps.
Read the court decisionRead the full story...Reprinted courtesy of
Michael L. DeBona, White and WilliamsMr. DeBona may be contacted at
debonam@whiteandwilliams.com