Cambridge Massachusetts Building Expert Directory

Zillow Topping Realogy Shows Web Surge for Housing Market

July 30, 2014 — Prashant Gopal and John Gittelsohn – Bloomberg
Zillow Inc. (Z)’s purchase of Trulia Inc. makes the online company such a force in U.S. real estate that its market value now surpasses that of Realogy Corp., owner of renowned brokerage brands from Coldwell Banker to Century 21. Zillow, the biggest U.S. real estate website, has seen its market value jump to about $5.83 billion from $4.99 billion on July 23, the day before Bloomberg News reported the deal talks with rival Trulia. Realogy, the largest residential brokerage operator, has a market value of about $5.47 billion, compared with $5.67 billion last week, data compiled by Bloomberg show. The shift underscores the growing role of the Web in U.S. home sales as buyers start their hunt for homes and mortgages online and rely less on real estate agents, a migration that has taken longer than in industries such as music or travel. While Zillow is unlikely to compete directly with brokers, whose ad dollars are its top revenue source, buying Trulia (TRLA) gives it more command over marketing fees, sparking concerns among Realtors such as Stephen FitzMaurice that costs will rise. Mr. Gopal may be contacted at pgopal2@bloomberg.net; Mr. Gittelsohn may be contacted at johngitt@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal and John Gittelsohn, Bloomberg

Another Colorado Construction Defect Reform Bill Dies

May 07, 2014 — Beverley BevenFlorez-CDJ STAFF
Colorado construction defects reform Senate Bill 220 died when “Senate President Morgan Carroll, D-Aurora, declined to call a second committee to hear” the bill, according to Ed Sealover writing for the Denver Business Journal. Sen. Carroll declared that the “bill backers” did not incorporate any of the “suggestions she or House Speaker Mark Ferrandino had given them.” “SB 220 would have required condo-unit owners to submit to alternative-dispute resolution such as arbitration or mediation if the unit developer required it,” Sealover reported. “And it would have required that a majority of members of a homeowners association agree to file a lawsuit, a standard significantly larger than the two-person bar that now must be met.” Bill Cosponsor Sen. Mark Scheffel, R-Castle Rock, “believes litigation reform” will become “an election issue and” that it “has strong momentum heading into the 2015 session.” Read the court decision
Read the full story...
Reprinted courtesy of

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

Florida SB 2022-736: Construction Defect Claims

February 07, 2022 — Kelly A. Johnson - Saxe Doernberger & Vita, P.C.
*Special thank you to SDV Law Clerk Iliriana Fteja for contributing to this article. A new bill (SB 2022-736) was recently introduced to the Florida Senate. The proposed amendments to the statutes of limitations and repose could significantly impact construction defect claims by effectively creating additional exposure to contractors and insurance carriers. The proposed bill requires all actions founded on the design, planning, or construction of an improvement to real property to be commenced within four years after the time to commence an action begins. Under the proposed amendment, the time to commence an action runs from the date of actual possession by the owner, the date of the issuance of a certificate of occupancy, the date of abandonment of construction if not completed, or the date of completion of the contract or termination of the contract between the professional engineer, registered architect, or licensed contractor and their employer. This provision would effectively alter the time to commence an action to whichever triggering event is earliest instead of the latest triggering event per the previous statute. Read the court decision
Read the full story...
Reprinted courtesy of Kelly A. Johnson, Saxe Doernberger & Vita, P.C.
Ms. Johnson may be contacted at KJohnson@sdvlaw.com

Real Estate & Construction News Round-Up (02/15/23) – Proptech Solutions, Supply Chain Pivots, and the Inflation Reduction Act

March 06, 2023 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
This week’s round-up explores how proptech could alleviate the financial burden of property owners’ vacant office space, manufacturing firms are bolstering the industrial real estate sector, a 200-MW Texas project is first to leverage IRA tax credit for stand-alone energy storage, and more.

Proptech could serve as an economic regenerator to the rise in empty office space that has recently become a major financial liability for businesses. (Joe Dyton, Connected Real Estate Magazine)
The global business process outsourcing (BPO) industry and accompanying real estate infrastructure that supports it should be aware of the potential impact of AI chatbots becoming capable of optimizing customer service with minimal human input. (Zain Jaffer, Forbes)
Industrial real estate is being bolstered by manufacturing firms increasingly returning their operations to the U.S., which was already one of the hottest commercial property sectors in the last decade. (JLL)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Fla. Researchers Probe 'Mother of All Sinkholes'

August 24, 2017 — Thomas F. Armistead - Engineering News-Record
It will take months to complete remediation of the largest sinkhole in Pasco County, Fla.’s recent history, county officials say. Seven houses have been lost or condemned since the sinkhole was reported at 7:21 a.m. on July 14. That day, two houses collapsed into the hole, which initially measured 225 ft long and 50 ft deep. As the cavity’s dimensions grew to between 260 ft and 180 ft, the county red-tagged five additional houses. Read the court decision
Read the full story...
Reprinted courtesy of Thomas F. Armistead, ENR
ENR may be contacted at ENR.com@bnpmedia.com

A Few Things You Might Consider Doing Instead of Binging on Netflix

April 13, 2020 — Garret Murai - California Construction Law Blog
Governments throughout the world have issued “shelter in place” orders requiring that residents stay at home except for “essential” purposes. As a result, in the United States, more than a third of Americans have been ordered to stay at home. This, in turn, has had a direct impact on construction projects which have slowed or have been temporarily shuttered altogether, and it will (not may) have an impact on the flow of project funds. So what can project owners and contractors do? We’ve got a few tips. 1. Read Your Contract, Paying Particular Attention to Force Majeure, No Damages for Delay and Notice Provisions For the most part, with the exception of statutory rights and remedies which we will discuss below, your contract spells out your rights and remedies should the proverbial “S” hit the fan. It is, in other words, the rules you agreed to, and you should know what those rules provide. Three provisions you should look for, and if they’re in your contract, you should review carefully are: (1) Force majeure provisions; (2) No damages for delay provisions; and (3) notice provisions. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Real Estate & Construction News Round-Up (08/24/22) – Local Law 97, Clean Energy, and IRA Tax Credits

September 26, 2022 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
This week’s round-up features the intersection of real estate and energy efficiency, including state efforts surrounding clean energy legislation, Inflation Reduction Act tax credits, hotel & hospitality sectors creating sustainable initiatives to reduce carbon emissions, and more.

In New York City, building owners try to figure out how to pay for upgrades needed to comply with regulations outlined in Local Law 97 that are intended to fight climate change. (Jane Margolies, The New York Times)
Maryland, Massachusetts, and New York approve clean energy legislation, enacting laws to promote electric vehicles as well as wind and solar energy. (ACEEE)
The Inflation Reduction Act (IRA), signed into law by President Biden this week, includes expanded tax credits expected to pivot building owners and property developers to make upgrades geared towards energy efficiency. (Jack Rogers, Globe St.)