Seattle Washington Building Expert Directory

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Not so Fast – Florida’s Legislature Overrules Gindel’s Pre-Suit Notice/Tolling Decision Related to the Construction Defect Statute of Repose

May 11, 2020 — Rahul Gogineni - The Subrogation Strategist
As discussed in a prior blog post, in Gindel v. Centex Homes, 2018 Fla.App. LEXIS 13019, Florida’s Fourth District Court of Appeal held that when the plaintiffs provided a pre-suit notice in compliance with §558.004 of Florida’s construction defect Right-to-Cure statute, Fla. Stat. §§ 558.001 to 558.005, et. seq., they commenced a “civil action or proceeding,” i.e. an “action,” within the meaning of Florida’s construction defect Statute of Repose, Florida Statue § 95.11(3)(c). Thus, the court held that the plaintiffs commenced their action prior to the time Florida’s 10-year statute of repose period ended. In overturning the lower court’s dismissal of the action, the court found that because the Right-to-Cure statute, §558 of the Florida Statutes, sets out a series of mandatory steps that must be taken prior to bringing a judicial action, filing pre-suit notice of claim sufficiently constituted an “action” for purposes of Florida’s Statute of Repose. For various reasons, the parties appealed the decision to the Supreme Court of Florida. In July of 2019, before the Florida Supreme Court could decide whether to hear the case, the Florida legislature passed legislation that effectively overruled the decision. To overrule the decision, the Florida Legislature modified § 558.004 of Florida’s Right-to-Cure statute to expressly state that a notice of claim served pursuant to the Right-to-Cure statute does not toll the 10-year statute of repose period for construction claims. See Fla. Stat. § 558.004(d). Read the court decision
Read the full story...
Reprinted courtesy of Rahul Gogineni, White and Williams LLP
Mr. Gogineni may be contacted at goginenir@whiteandwilliams.com

Haight Ranked in 2018 U.S. News - Best Lawyers "Best Law Firms" List

November 02, 2017 — Haight Brown & Bonesteel LLP
Haight Brown & Bonesteel LLP is listed in the 2018 U.S. News – Best Lawyers "Best Law Firms" list with five metro rankings in the following areas: Los Angeles

Tier 1 in Insurance Law
Tier 1 in Personal Injury Litigation - Defendants
Tier 1 in Product Liability Litigation - Defendants
Tier 2 in Personal Injury Litigation - Plaintiffs
Tier 2 in Product Liability Litigation - Plaintiffs

Read the court decision
Read the full story...
Reprinted courtesy of

Insurer’s Confession Of Judgment Through Post-Lawsuit Payment

June 25, 2019 — David Adelstein - Florida Construction Legal Updates
The recent opinion in the property insurance coverage dispute, Bryant v. Geovera Specialty Ins. Co., 44 Fla.L.Weekly D1232a (Fla. 4thDCA 2019), discusses the doctrine known as an insurer’s “confession of judgment.” In this case, an insured suffered water damage from a pipe leak. The insurer paid the insured $6,000 because of sublimits in the property insurance policy. There was a $5,000 sublimit for mold and a $1,000 sublimit for water leakage that occurs over a period of 14 days or more. The insured sued the insurer for covered water damage arguing that the sublimits did not apply. After the lawsuit was filed, an agreed order was entered that stayed the case pending an appraisal. The appraisal award did not apply the $1,000 sublimit to the water damage from the pipe leak and segregated out damage for mold. (The insurer already paid the mold sublimit). The insurer ended up paying the appraisal award for the water damage caused by the pipe leak after deducting its pre-lawsuit sublimit payment. The insurer paid the award and did NOT challenge the application of the $1,000 sublimit in court, although it could have since coverage issues are decided by courts. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Insurance Coverage Litigation Section to Present at Hawaii State Bar Convention

October 15, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The Hawaii State Bar convention will be on October 24, 2014, at the Hawaiian Hilton. The Insurance Coverage Litigation Section will make a presentation from 8:30 a.m. to 11:45 a.m. Three presentations will be made. First, Richard C. Mosher (Anderson Kill), Kathy Dang (Marsh), and Beau Monday (Hawaiian Telcom) will discuss cyber-liability claims and insurance options. Next, David R. Harada-Stone (Tom Petrus & Miller) and I (Damon Key Leong Kupchak Hastert) will address "occurrences," i.e., deciding on and the impact of determining the number of occurrences in particular factual settings. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

White and Williams Recognizes Women’s History Month: Remembering Virginia Barton Wallace

April 08, 2024 — White and Williams LLP
March is Women’s History Month – a month dedicated to the accomplishments and history of women in the United States. The theme for International Women’s Day, which is this Thursday March 7, is “Inspire Inclusion.” White and Williams LLP is dedicated to understanding, valuing and inspiring inclusion in the field of law White and Williams is proud of the women who have become leaders in the firm’s history, starting with Virginia “Ginny” Barton Wallace, an extraordinarily accomplished pioneer among female attorneys. She joined the firm immediately after graduating from University of Pennsylvania School of Law in 1950, and in 1961, Ginny became the first woman to become the first female partner not only at White and Williams but also at any law firm in Philadelphia. Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

No Coverage for Building's First Collapse, But Disputed Facts on Second Collapse

January 10, 2018 — Tred R. Eyerly – Insurance Law Hawaii

While building's first collapse was not covered, there were disputed facts regarding the second collapse, leading to a reversal of the order granting summary judgment to the insurer on both collapses. Intergroup Int'l Ltd. v. Cincinnati Ins. Cos, 2017 Ohio app. LEXIS 5099 (Ohio Ct. App. Nov. 22, 2017). Intergroup bought a building after it was inspected. While leaks on the roof were repaired and a roof truss that was sagging was replaced, the inspector found the roof to be in good shape.

Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii

Mr. Eyerly may be contacted at te@hawaiilawyer.com

Delaware “occurrence” and exclusions j(5) and j(6)

June 10, 2011 — CDCoverage.com

In Goodville Mut. Cas. Co. v. Baldo, No. 09-338 (D. Del. June 2, 2011), claimants condominium association and unit owners sued project developer Rehoboth and general contractor Capano seeking damages because of moisture penetration property damage to common elements and individual units resulting from construction defects. Rehoboth and Capano filed a third party complaint against insured property manager Baldo alleging that, if Rehoboth and Capano were liable to claimants, Baldo was also liable because of Baldo’s failure to properly manage, maintain, and repair the property

Read the full story…

Reprinted courtesy of CDCoverage.com