Seattle Washington Building Expert Directory

Quick Note: COVID-19 Claim – Proving Causation

August 03, 2020 — David Adelstein - Florida Construction Legal Updates
In certain jurisdictions, the number of people testing positive for COVID-19 is on the rise. As this occurs, there is the possibility that a construction project will have to deal with one or more workers testing positive. That is the current reality. If the dialogue has not occurred before, now is the time to discuss any enhanced measures—above OSHA guidelines—that could be implemented to address this reality and mitigate the risk. Part of the reality, though, is that regardless of the enhanced measures and mitigation, it is impossible to truly prevent this risk. No one disputes COVID-19. There may be a dispute as to whether COVID-19 constitutes a force majeure event or some other event, however, before you start labeling it, you still NEED TO PROVE the impact caused by COVID-19. There needs to be a cause-and-effect relationship so you can address (i) how this impacted the critical path of your schedule and/or (ii) how this impacted labor productivity. In other words, you need to prove causation. Stating there was a delay or loss of productivity without establishing the cause-and-effect relationship (i.e, causation) provides no value because it does not support the production impact or time extension and, without either, there is no basis for additional compensation (even if you establish it should be deemed an excusable, compensable delay). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

U.K. Construction Resumes Growth Amid Resurgent Housing Activity

October 07, 2016 — Scott Hamilton – Bloomberg
The U.K. construction industry returned to growth in September as a measure of housing activity jumped the most since 2013. IHS Markit said on Tuesday that its Purchasing Managers Index jumped to 52.3 from 49.2 in August. It was the highest level in six months and ended a three-month run of readings below 50, the threshold that divides expansion from contraction. The figures add to evidence that the economy is performing better than many predicted following the June decision to leave the European Union. Traders increasingly expect the Bank of England to refrain from adding to its August stimulus package this year. Read the court decision
Read the full story...
Reprinted courtesy of Scott Hamilton, Bloomberg

Eleven Newmeyer Dillion Attorneys Named to 2023 U.S. News Best Lawyers in Multiple Practice Areas

August 29, 2022 — Newmeyer Dillion
NEWPORT BEACH, Calif. – August 18, 2022 – Prominent business and real estate law firm Newmeyer Dillion is pleased to announce that eleven of the firm’s attorneys were recently selected for inclusion and will be recognized in their respective areas in The Best Lawyers in America© 2023. Additionally, Greg Dillion, Thomas Newmeyer and Michael McClellan have been selected to Best Lawyers 2023 Lawyer of the Year list in Litigation - Construction, Construction Law and Litigation - Real Estate respectively. The eleven 2023 Best Lawyers are:

Best Lawyers is the oldest peer-review publication for the legal profession. Attorneys are chosen through intensive peer-review surveys in which leading lawyers evaluate their professional peers. Best Lawyers listings are published in almost 70 countries worldwide and are recognized for their reliable and unbiased selections. Read the court decision
Read the full story...
Reprinted courtesy of

Effective July 1, 2022, Contractors Will be Liable for their Subcontractor’s Failure to Pay its Employees’ Wages and Benefits

July 25, 2022 — Edward O. Pacer & David J. Scriven-Young - Peckar & Abramson
On June 10, 2022, Illinois Governor J.B. Pritzker signed two House Bills that amend the Illinois Wage Payment & Collections Act, 820 ILCS 115 et. seq. (“Wage Act”), to provide greater protection for individuals working in the construction trades against wage theft in a defined class of projects. Pursuant to this new law, every general contractor, construction manager, or “primary contractor,” working on the projects included in the Bill’s purview will be liable for wages that have not been paid by a subcontractor or lower-tier subcontractor on any contract entered into after July 1, 2022, together with unpaid fringe benefits plus to attorneys’ fees and costs that are incurred by the employee in bringing an action under the Wage Act. These amendments to the Wage Act apply to a primary contractor engaged in “erection, construction, alteration, or repair of a building structure, or other private work.” However, there are important limitations to the amendment’s applicability. The amendment does not apply to projects under contract with state or local government, or to general contractors that are parties to a collective bargaining agreement on a project where the work is being performed. Additionally, the amendment does not apply to primary contractors who are doing work with a value of less than $20,000, or work that involves only the altering or repairing of an existing single-family dwelling or single residential unit in a multi-unit building. Reprinted courtesy of Edward O. Pacer, Peckar & Abramson and David J. Scriven-Young, Peckar & Abramson Mr. Pacer may be contacted at epacer@pecklaw.com Mr. Scriven-Young may be contacted at dscriven-young@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Can I Record a Lis Pendens in Arizona if the Lawsuit is filed Another Jurisdiction?

September 26, 2022 — Ben Reeves - Snell & Wilmer Real Estate Litigation Blog
Recent research I did on a case led me to the conclusion that Arizona law recognizes foreign litigation (i.e., a lawsuit filed outside of Arizona) as a justification for the recording of a lis pendens against real property located within Arizona. See TWE Retirement Fund Trust v. Ream, 198 Ariz. 268 (Ct. App. 2000). Apparently, there’s some debate about whether foreign litigation can support a local lis pendens. See Boca Petroco, Inc. v. Petroleum Realty II, 285 Ga. 487 (Ga. 2009). As noted in the TWE case, Arizona’s lis pendens statute (A.R.S. 12-1191) does not discriminate between local or foreign “actions.” As such, if litigation is pending anywhere that affects Arizona real property, a lis pendens can (and probably should) be filed. Reprinted courtesy of Ben Reeves, Snell & Wilmer Mr. Reeves may be contacted at breeves@swlaw.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

David M. McLain named Law Week Colorado’s 2015 Barrister’s Best Construction Defects Lawyer for Defendants

September 17, 2015 — Sheri Roswell – Colorado Construction Litigation
It is my sincere pleasure to announce Law Week Colorado named my friend and partner, Dave McLain, as the 2015 Barrister’s Best Construction Defects Lawyer for Defendants. Law Week Colorado’s summary of David’s accomplishments includes the following recognition:

David McLain has set himself apart in the heated area of construction defects litigation as a founding member of his firm and as a member of several associations that serve developers. As one of the most connected and most vocal members of this area of law, we certainly know whom to go to when the construction defects issue inevitably bubbles up again.

I can say with pride and certainty, that there is no one more deserving of such recognition in the legal and construction community than David. I have had the honor of working side by side with David since he began practicing law. Together, fourteen years ago, we founded Higgins, Hopkins, McLain & Roswell, LLC with a vision of serving the construction industry at the highest level. Our firm’s Mission Statement states that “HHMR exists to embody and exemplify the principles of service and stewardship. In everything we do, we focus on serving our clients selflessly and to the best of our ability.” David lives our values each and every day. Read the court decision
Read the full story...
Reprinted courtesy of Sheri Roswell, Higgins, Hopkins, McLain & Roswell, LLC
Ms. Roswell may be contacted at roswell@hhmrlaw.com

Latosha Ellis Joins The National Black Lawyers Top 40 Under 40

January 20, 2020 — Hunton Insurance Recovery Blog
Latosha M. Ellis, an associate in Hunton Andrews Kurth’s Insurance Coverage Practice, was recently named to The National Black Lawyers Top 40 Under 40 class of 2019. The professional honorary association recognizes attorneys under 40 from each state who demonstrate superior leadership, reputation, influence, stature and profile as a black lawyer. Selection is by invitation only following a multi-phase review process that includes peer nominations and third party research. Read the court decision
Read the full story...
Reprinted courtesy of Hunton Andrews Kurth LLP

Connecticut Supreme Court Finds Faulty Work By Subcontractor Constitutes "Occurrence"

July 31, 2013 — Tred Eyerly, Insurance Law Hawaii
The U.S. District Court in Alabama certified a question to the Connecticut Supreme Court: Is damage to a project caused by faulty workmanship "property damage" resulting from an "occurrence"? With some qualification, the Connecticut Supreme Court answered in the affirmative. Capstone Building Corp. v. Am. Motorists Ins. Co., SC 18886 (Conn. June 11, 2013). Captsone Development agreed to coordinate and supervise construction on a building at the University of Conneticut. Capstone Building was the general contractor. UConn secured an OCIP policy from American Motorist Insurance Company ("AMICO"). More than three years after completion, UConn notified the insureds of alleged defects in the project, including elevated levels of carbon monoxide. The source of the leak was the individual hot water heaters in residential units and insufficient draft of exhaust from the heater.Other defects were found during an investigation. The insureds tendered to AMICO. Coverage was denied because the liability arose out of the insureds' own work.The insureds settled with UConn, paying $1 million each. The insureds then sued AMICO in Alabama and the question was certified to the Connecticut Supreme Court. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES