FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Employee Screening and Testing in the Covid-19 Era: Getting Back to Work

August 10, 2020 — Aaron C. Schlesinger & Shannon D. Azzaro - Peckar & Abramson
Currently Available Workplace Protocols for Employers Employers seeking to minimize the risk of COVID-19 transmission in the workplace should consider from among the three currently available protocols: Written Questionnaires; Temperature Checks; and Viral or Diagnostic Testing. When implementing a screening or testing protocol, employers should explain the following in writing to employees: (1) the specific screening process or test utilized by the employer; (2) employee compliance expectations and any consequences for a refusal to participate; (3) how employee privacy will be protected; (4) if screening, the general benchmarks that indicate the employee has “passed” (e.g., temperature below 100.4ºF, per CDC guidelines); and (5) the outcome of an unsuccessful screen or test (e.g., being sent home from the workplace). Employers must also ensure that those administering the screening and/or testing are properly trained, and that appropriate written acknowledgements are obtained from employees consenting to the applicable protocol. Reprinted courtesy of Aaron C. Schlesinger, Peckar & Abramson and Shannon D. Azzaro, Peckar & Abramson Mr. Schlesinger may be contacted at aschlesinger@pecklaw.com Ms. Azzaro may be contacted at sazzaro@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

---

Massachusetts High Court: Attorney's Fee Award Under Consumer Protection Act Not Covered by General Liability Insurance Policy

September 19, 2022 — Jeffrey J. Vita & David G. Jordan - Saxe Doernberger & Vita, P.C.
In the case of Vermont Mutual Insurance Co. v. Poirier, 189 N.E.3d 306 (Mass. 2022), Massachusetts’ Supreme Judicial Court concluded that an award of attorney's fees pursuant to Chapter 93A (Massachusetts’ Consumer Protection Act) is not covered under an insured’s general liability insurance policy. Applying Massachusetts law, the Court found that a statutory award of attorney’s fees stemming from a bodily injury claim is not reasonably considered “damages because of bodily injury” or “costs taxed against the insured” so as to trigger general liability coverage. Facts of the Case A Servpro company (owned by Mr. and Mrs. Poirier) was hired to clean up a basement after a sewage spill. The owners of the home were injured by fumes from chemicals used in the cleanup and accordingly brought suit against the Poiriers and their Servpro business. In the lawsuit, the homeowners alleged negligence, breach of contract, and also a Chapter 93A claim, asserting breach of warranty of merchantability and warranty of fitness for a particular purpose. Prior to trial, the plaintiffs waived the negligence and breach of contract claims and sought a bench trial on the Chapter 93A claims alone. Reprinted courtesy of Jeffrey J. Vita, Saxe Doernberger & Vita, P.C. and David G. Jordan, Saxe Doernberger & Vita, P.C. Mr. Vita may be contacted at JVita@sdvlaw.com Mr. Jordan may be contacted at DJordan@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

9 Positive Housing Statistics by Builder

March 05, 2015 — Beverley BevenFlorez-CDJ STAFF
Builder Magazine presented “9 housing stats to start off spring selling season.” For instance, the rate of U.S. homeownership in the fourth quarter of 2014, according to the U.S. Census Bureau, was 63.9% and there were 728,000 housing starts in December of 2014, according to the NAHB. Furthermore, 80% of contracting firms plan to expand payrolls in 2015. Read the court decision
Read the full story...
Reprinted courtesy of

---

Obama Says Keystone Decision May Be Announced in Weeks or Months

March 05, 2015 — Justin Sink – Bloomberg
(Bloomberg) -- President Barack Obama said a decision on whether to approve the Keystone XL pipeline is possible in weeks or months. The president told Reuters in an interview Monday that the decision definitely “will happen before the end of my administration.” Asked to be specific, he said, “Weeks or months.” Read the court decision
Read the full story...
Reprinted courtesy of Justin Sink, Bloomberg
Mr. Sink may be contacted at jsink1@bloomberg.net

---

Traub Lieberman Attorneys Named 2019 Super Lawyers

November 04, 2019 — Traub Lieberman
Related Attorneys: Jonathan R. Harwood, Michael K. Kiernan, Michael S. Knippen, Meryl R. Lieberman, Christopher Russo, Scot E. Samis, Lisa L. Shrewsberry, Stephen D. Straus, Richard K. Traub, Cheryl P. Vollweiler, Brian C. Bassett, Jessica N. Kull, Jeremy S. Macklin, Dana A. Rice, Burks A. Smith, III, Jason Taylor Ten Traub Lieberman attorneys have been named 2019 Super Lawyers and seven named 2019 Rising Stars. The honored attorneys represent five of the firm's seven offices and nearly all of its service areas. Super Lawyers, a Thomson Reuters business, is a rating service of outstanding lawyers from more than 70 practice areas, who have attained a high degree of peer recognition and professional achievement. The annual selections are made using a patented multiphase process that includes a statewide survey of lawyers, an independent research evaluation of candidates and peer reviews by practice area. Read the court decision
Read the full story...
Reprinted courtesy of

---

Hong Kong Buyers Queue for New Homes After Prices Plunge

July 09, 2014 — Michelle Yun – Bloomberg
On a Saturday morning in mid-June, thousands wait, crammed into Hong Kong’s Fortune Metropolis mall, across Victoria Harbor from the main business district, their eyes locked on large elevated screens. Cheers erupt when numbers flash, indicating the lucky ticket holders in the crowd. They have paid HK$150,000 ($19,354) to enter a lottery that prioritizes buyers of apartments at City Point, a seven-tower development that billionaire Li Ka-shing’s Cheung Kong Holdings Ltd. (1) is building. More than 5,000 homebuyer-hopefuls are vying for 442 units, or about 11 for every home that went on sale the weekend of June 14. Housing sales in Hong Kong are rising after government efforts to cool soaring prices led transactions to plunge last year to the lowest since at least 2002. A drop in mortgage rates and discounts from builders are luring back buyers of new homes after their price fell as much as 20 percent since October. Read the court decision
Read the full story...
Reprinted courtesy of Michelle Yun, Bloomberg
Ms. Yun may be contacted at myun11@bloomberg.net

---

Texas Windstorm Insurance Agency Under Scrutiny

April 05, 2011 — Beverley BevenFlorez CDJ STAFF

Representative Larry Taylor has introduced a bill in the Texas Legislature (HB 2818) that would further regulate the Texas Windstorm Insurance Agency (TWIA). According to Taylor, “In order to be adequately prepared for future hurricane seasons, it is imperative that TWIA be operating at maximum efficiency, that the Reserve Trust Fund be solvent and that the agency have adequate management measures in place to protect consumers and ensure that claims are paid in a timely manner. House Bill 2818 is an important step in the right direction toward restoring public confidence in TWIA.”



HB 2818 includes measures that would create an expert panel that would advise the commissioner on how to evaluate loss from the storm, and a greater transparency of TWIA Board meetings and actions.



In addition, the Texas Department of Insurance (TDI) has placed TWIA on Administrative Oversight. According to TDI, “While under Administrative Oversight, the Department may require its prior review and approval of executive decisions, certain expenditures, and other transactions. The insurer is required to fully cooperate with the Department and provide complete and timely disclosure of all information responsive to Department requests.”



Read the full story (Rep. Taylor’s Press Release)...



Read the full story (Texas Department of Insurance’s Press Release)...

Read the court decision
Read the full story...
Reprinted courtesy of

---