Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season
January 13, 2020 —
David Adelstein - Florida Construction Legal UpdatesThere are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be.
For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:
[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season.
Meridian Engineering, 2019 WL at *7 (internal citations omitted)
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Replacement of Gym Floor Due to Sloppy Paint Job is Not Resulting Loss
January 02, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe court granted the insurer's motion for summary judgment finding damage to the gym floor due to a poor paint job was not a resulting loss. Bob Robinson Commercial Flooring, Inc. v. RLI Ins,. Co., 2023 U.S. Dist. LEXIS 196105 (D. Ark. Nov. 1, 2023).
Bob Robinson Commercial Flooring (BRCF) submitted a bid to the general contractor, Nabholz Construction Corporation, to install a vinyl athletic floor and striping at a middle school. The job also included the painting of a "Wildcat" logo the main gym floor. Therefore, BRCF's job was to install floors with proper painting and striping. Robert Liles and Robert Lines Parking Lot Services was the subcontractor hired to do the painting and striping. BRCF did not supervise or inspect Liles' work while it was ongoing.
Nabholz informed BRCF that there were problems with the floor painting, including crooked lines, incorrect markings, misplacement of the three point lines for the basketball surface, drips, smudges, etc. The gym floor was eventually rejected due to the nature of the vinyl flooring, once primer and paint were applied, the paint could not be removed and repainted. BRCF had to hire a new subcontractor to remove the flooring, install new flooring and then paint new lines. The cost for removal and replacement was $134,188.95.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
LaGuardia Airport Is a Mess. An Engineer-Turned-Fund Manager Has a Fix
May 26, 2019 —
Sree Vidya Bhaktavatsalam - BloombergThierry Déau’s engineering training in France led him early in his career to building government-funded infrastructure. But it was his entrepreneur father back home in Martinique who inspired him to strike out on his own in 2005. He started Paris-based Meridiam to finance, build, and manage long-term projects. Now, with €7 billion ($7.83 billion) in seven funds and nine offices across Europe, the Middle East, Africa, and North America, Meridiam is playing a key role in high-profile projects such as the upgrade of New York’s LaGuardia Airport and a road tunnel under the Port of Miami. Déau describes Meridiam’s investment approach in an interview with Bloomberg Markets.
Read the court decisionRead the full story...Reprinted courtesy of
Sree Vidya Bhaktavatsalam, Bloomberg
NJ Court Reaffirms Rule Against Coverage for Faulty Workmanship Claims and Finds Fraud Claims Inherently Intentional
September 20, 2021 —
Anthony L. Miscioscia & Frank J. Perch, III - White and Williams LLPAwarding summary judgment to an insurer under both liability and directors & officers (D&O) coverage parts, a New Jersey trial court reaffirmed the principle that claims of defective workmanship without resulting “property damage” are not covered under a general liability policy, and further dismissed claims for fraud and breach of fiduciary duty, finding that such claims were inherently intentional and do not state a covered “occurrence.”
In Velez v. AR Management Company, et al., 2021 N.J. Super. Unpub. LEXIS 1675 (Law Div. Bergen Co. Aug. 10, 2021), owners of a condominium unit rebuilt after a fire sued the condominium association, several association board members, the association’s property management company and the general contractor for the reconstruction work. The owners’ suit alleged faulty workmanship and incomplete repairs. In addition, the owners asserted fraud and breach of fiduciary duty claims against the management company, alleging conflicts of interest and self-dealing between the management company and the general contractor, which had common ownership.
In a third-party complaint, the management company sought coverage from the condo association’s liability and D&O insurer. The court dismissed the D&O coverage claim, noting that the management company was not a director or officer or otherwise entitled to insured status for the D&O coverage part.
Reprinted courtesy of
Anthony L. Miscioscia, White and Williams LLP and
Frank J. Perch, III, White and Williams LLP
Mr. Miscioscia may be contacted at misciosciaa@whiteandwilliams.com
Mr. Perch may be contacted at perchf@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Court Grants Summary Judgment to Insurer in HVAC Defect Case
August 04, 2011 —
CDJ STAFFThe US District Court in Colorado has determined in the case of RK Mechanical, Inc. v. Travelers Property Casualty Company of America that Travelers did not breach its insurance contract when it refused to cover RK Mechanical.
RK Mechanical performed an HVAC installation for a residential project for which J.E. Dunn Rocky Mountain was the general contractor. As part of the work, RK “installed approximately one hundred seventy-one CPVC flanges, which were manufactured by Charlotte Pipe and Foundry Company.” Two of these flanges failed in June, 2009 leading to water damage. RK replaced the cracked flanges and engaged in water remediation. “Travelers paid Dunn and RK for the costs associated with the water damage associated with the Flange Failure.” The court notes that Travelers did not pay for the cracked flanges, however.
Subsequently, RK examined the remaining flanges, finding many cracked ones. These were replaced with new ones. Later, all the Charlotte flanges were replaced with ones from another manufacturer. RK applied for coverage.
All sides brought in their experts: “Microbac Laboratories, Inc. prepared a report on behalf of RK concluding that the Flange Failure was due, in part, to an assembly or workmanship defect in addition to manufacturing defects in the flanges. Higgins & Associates prepared a report on behalf of Travelers concluding that the flanges failed due to improper installation. Plastic Failure Labs prepared a report on behalf of the flange manufacturer concluding that the flanges failed due to improper installation by RK.”
At this point, Travelers denied coverage. RK sued alleging that the coverage for flange failure and water damage implicitly includes mitigation costs. The court rejected this claim, noting it would do so even if Travelers had paid for the replacement of the first two flanges. Nor did the court find that replacement of the faulty flanges is not "a covered cause of loss." RK also argued that as it was required to mitigate, Travelers was obligated to cover costs. However, the court found that “the mitigation costs expended by RK were not incurred in an effort to avoid damages from a potential breach of contract by Travelers.” The court additionally noted that despite RK’s claims, the Colorado courts have not found a common law duty to mitigate. Finally, the court found that the exclusions in the policy were not in violation of public policy.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
No Coverage Under Anti-Concurrent Causation Clause
October 02, 2015 —
Tred R. Eyerly – Insurance Law HawaiiThe policy's anti-concurrent causation clause blocked coverage for damage to the home caused by wind and flood. Clarke v. Travco Ins. Co., 2015 U.S. Dist. LEXIS 104267 (S.D.N.Y. Aug. 7, 2015).
The insured's home was located about twenty feet from the Hudson River. Hurricane Sandy caused the river to rise, creating damage to the insured's home. The insured did not have flood insurance. During the storm, water flooded the lower level of the house to a level of about four feet. Further, a wooden dock from another property, approximately fifteen feet by ten feet, entered the property and came to rest within the lower level.
The insured submitted a claim under his homeowner's policy to Travco Insurance Company. An investigator concluded that the cause of damage to the home was flood/water. The claim was denied.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
2018 Legislative Changes Affecting the Construction Industry
June 06, 2018 —
Melinda S. Gentile - Peckar & AbramsonThe 2018 Florida Legislative Session recently concluded and a number of important construction-related House Bills (HB) and Senate Bills (SB) were presented during the Session. Florida Governor Rick Scott has 15 days to act on the legislation once each Bill has passed the House and Senate. Bills signed by the Governor go into effect on July 1, 2018, unless indicated otherwise. These Bills may impact General Contractors and Construction Managers in a number of ways, not the least of which is the period of time that a cause of action may be initiated for the design, planning or construction of an improvement.
Read the court decisionRead the full story...Reprinted courtesy of
Melinda Gentile, Peckar & AbramsonMs. Gentile may be contacted at
mgentile@pecklaw.com
It’s All a Matter of [Statutory] Construction: Supreme Court Narrowly Interprets the Good Faith Dispute Exception to Prompt Payment Requirements in United Riggers & Erectors, Inc. v. Coast Iron & Steel Co.
May 30, 2018 —
Erinn Contreras & Joy O. Siu - Sheppard Mullin Construction & Infrastructure Law BlogOn May 14, 2018, the California Supreme Court issued its opinion in United Riggers & Erectors, Inc. v. Coast Iron & Steel Co., No. S231549, slip. op. (Cal. Sup. Ct. May 14, 2018). In it, the Court narrowly construed the “good faith” exception to the general rule that a direct contractor must make retention payments to its subcontractors within 10 days of receiving any retention payment. The exception provides that “[i]f a good faith dispute exists between the direct contractor and a subcontractor, the direct contractor may withhold from the retention to the subcontractor an amount not in excess of 150 percent of the estimated value of the disputed amount.” Cal. Civ. Code section 8814(c).
Reprinted courtesy of
Erinn Contreras, Sheppard Mullin and
Joy O. Siu, Sheppard Mullin
Ms. Contreras may be contacted at econtreras@sheppardmullin.com
Ms. Siu may be contacted at jsiu@sheppardmullin.com
Read the court decisionRead the full story...Reprinted courtesy of