Fire Consultants Cannot Base Opinions on Speculation
May 20, 2019 —
Christopher Konzelmann - The Subrogation StrategistLarsen v. 401 Main St. Inc., 302 Neb. 454 (2019), involved a fire originating in the basement of the Quart House Pub (Pub) in Plattsmouth, Nebraska that spread to and damaged Plattsmouth Chiropractic Center, Inc., a neighboring business. Fire investigators could not enter the building because the structure was unsafe and demolished. The chiropractic center nevertheless sued the Pub alleging that its failure to maintain and replace basement mechanical equipment caused ignition.
To prove its claim, the plaintiff retained a mechanical engineer who reviewed documents and concluded that the fire “originated from a failure of one of the items of mechanical equipment located in the area of the [basement] boiler.” Importantly, however, the consultant could not determine the root cause of the fire, could not eliminate the possibility that the fire originated in a compressor, and could not rule out the building’s electrical service as the ignition source because it was outside his area of expertise. The consultant nevertheless found that the fire most likely would not have occurred if the Pub had regularly serviced and replaced the equipment when needed.
Read the court decisionRead the full story...Reprinted courtesy of
Christopher Konzelmann, White and Williams LLPMr. Konzelmann may be contacted at
konzelmannc@whiteandwilliams.com
Hunton Insurance Coverage Partner Lawrence J. Bracken II Awarded Emory Public Interest Committee’s 2024 Lifetime Commitment to Public Service Award
February 26, 2024 —
Hunton Insurance Recovery BlogOn February 7, the Emory Public Interest Committee (EPIC) honored insurance coverage partner Lawrence (Larry) J. Bracken II with their 2024 Lifetime Commitment to Public Service Award at the annual
EPIC Inspiration Awards. As one of the Emory University School of Law’s signature events, the Inspiration Awards celebrate members of the community who do extraordinary work in the public interest and provide funding for public interest summer jobs.
Larry has more than 37 years of experience litigating insurance coverage, class action and commercial cases in federal and state courts throughout the United States. He represents policyholders in insurance coverage litigation and arbitration, and is a Fellow of the American College of Coverage Lawyers. Larry also has litigated class actions and other complex commercial disputes for more than three decades. Pro bono representation of clients in habeas corpus, prisoner rights, and landlord-tenant litigation is an important part of his practice. Larry currently serves as the President of the Board of Directors of the Atlanta Volunteer Lawyers Foundation.
Read the court decisionRead the full story...Reprinted courtesy of
Hunton Andrews Kurth LLP
MTA Debarment Update
December 02, 2019 —
Steven M. Charney, Gregory H. Chertoff & Paul Monte - Peckar & Abramson, P.C.Alliance for Fair and Equitable Contracting Today, Inc., a nonprofit formed by five trade associations, including the GCA, the BTEA and the NY Building Congress, has sued the Metropolitan Transportation Authority over rules that debar contractors for delays and cost overruns on MTA projects without regard to the reasons for the delays and cost overruns.
As described in our prior client alert (see
here), the current rules automatically debar firms that are determined to have gone over the MTA approved contract price or time by more than 10%. The rules do not consider mitigating circumstances. Delays and cost overruns are often caused by unforeseen conditions, design errors and omissions, and changes requested by the MTA. The MTA’s rules could lead contractors to absorb additional costs they shouldn’t be responsible for rather than face the risk of being debarred. As argued in Alliance’s action, “Debarment is the death penalty for a public works contractor, and not just in New York. A debarment by the MTA could result in debarment nationwide, given that public and private contractors throughout the country commonly inquire about bidders’ debarment history when considering project bids. The Debarment Statute and MTA Regulations thus effectively export an unreasonable law not only throughout New York State, but to all other states as well.”
Reprinted courtesy of Saxe Doernberger & Vita, P.C. attorneys
Steven M. Charney,
Gregory H. Chertoff and
Paul Monte
Mr. Charney may be contacted at scharney@pecklaw.com
Mr. Chertoff may be contacted at gchertoff@pecklaw.com
Mr. Monte may be contacted at pmonte@pecklaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
Illinois Supreme Court Announces Time Standards for Closing Out Cases
April 11, 2022 —
Zachary Shelton - Lewis Brisbois(April 4, 2022) - Beginning July 1, 2022, Illinois trial courts will begin imposing new time standards for closing out pending cases. This change follows the Illinois Supreme Court’s March 25, 2022 announcement setting new time standards for case closure in trial courts. This announcement will apply to all cases filed in the State of Illinois on or after January 1, 2022.
According to the recent announcement, the purpose of the new Time Standards Order (the Order) is to assist Illinois circuit courts with “meeting their fundamental obligation to resolve disputes fully, fairly, and promptly” by establishing a uniform, statewide expectation for parties, attorneys, and judges regarding the status of cases that will require each court to evaluate its actual performance compared to a statewide expectation.
Read the court decisionRead the full story...Reprinted courtesy of
Zachary Shelton, Lewis BrisboisMr. Shelton may be contacted at
Zachary.Shelton@lewisbrisbois.com
What is a Subordination Agreement?
May 06, 2019 —
Bremer Whyte Brown & O'Meara LLPPut simply, a subordination agreement is a legal agreement which establishes one debt as ranking behind another debt in the priority for collecting repayment from a debtor. It is an arrangement that alters the lien position. Without a subordination clause, loans take chronological priority which means that a deed of trust recorded first will be considered senior to all deeds of trusts recorded after. As such, the oldest loan becomes the primary loan, with first call on any proceeds from a sale of a property. However, a subordination agreement acknowledges that one party’s claim or interest is inferior to that of another party in the event that the borrowing entity liquidates its assets. Further, shareholders are subordinate to all creditors.
The junior debt is referred to as a “subordinated debt”, and the debt which has a higher claim to any assets is the senior debt. Often, the borrower does not have enough funds to pay all debts, and lower priority debts may receive little or no repayment. For example, if a business has $400,000 in senior debt, $100,000 in subordinated debt, and a total asset value of $420,000, upon liquidation of the company, only the senior debtholder will be paid in full. The remaining $20,000 will be distributed among the subordinated debtholders. Subordinated debts are, therefore, riskier and lenders will require a higher interest rate as compensation.
Read the court decisionRead the full story...Reprinted courtesy of
Bremer Whyte Brown & O'Meara LLP
California’s Labor Enforcement Task Force Continues to Set Fire to the Underground Economy
February 16, 2016 —
Evelin Y. Bailey – California Construction Law BlogIf you’re a fan of the Hunger Games trilogy, either the books or the movies, you’re likely familiar with “The Hob,” the black market in District 12 where people buy and sell banned items. It’s where bow-wielding protagonist Katniss Everdeen and her childhood friend Gale Hawthorne sell their poached game and where, in the movie but not the book (what can we say, we’re fans), Katniss obtains the “mockingjay” pin which she is later associated with. While The Hob is largely ignored by soldiers of the totalitarian “Capitol,” in the third book Catching Fire, the Hob is reduced to a pile of rubbish and ash by the Capital as an example to punish the insurrectionists led by Katniss.
The Labor Enforcement Task Force (LETF), a joint task force composed of several of California’s agencies including the Contractors State License Board, Department of Industrial Relations and Employment Development Department is also setting fire, at least figuratively, to California’s underground economy. See our earlier post Joint Labor Task Force Targets Underground Economy for further background on LETF.
Read the court decisionRead the full story...Reprinted courtesy of
Evelin Y. Bailey, Wendel Rosen Black & Dean LLPMs. Bailey may be contacted at
ebailey@wendel.com
A Court-Side Seat: Permit Shields, Hurricane Harvey and the Decriminalization of “Incidental Taking”
May 31, 2021 —
Anthony B. Cavender - Gravel2GavelThis is a brief review of some of the significant environmental (and administrative law decisions) released the past few weeks.
THE U.S. SUPREME COURT
On April 22, 2021, the Court decided two important administrative law cases: Carr, et al. v. Saul and AMG Capital Management v. Federal Trade Commission.
Carr, et al. v. Saul
In this case, the constitutionality of Social Security Administrative Law Judges (ALJs) hearing disability claims disputes was at issue. More precisely, were these ALJs selected in conformance with the Appointments Clause of the Constitution? A similar issue was litigated in the case of Lucia v. Securities and Exchange Commission. There, the Court held that many of the agency’s ALJs were not selected in conformance with the Appointment’s Clause. Here, the Court held that this issue could be decided by the courts without compelling the litigants to first exhaust their administrative remedies. Thousands of ALJs are employed by the federal government, and it may take some time to resolve this question for every agency.
AMG Capital Management v. Federal Trade Commission
In this case, the court held, unanimously, that the Commission does not presently have the authority to employ such equitable remedies as restitution or disgorgement.
Read the court decisionRead the full story...Reprinted courtesy of
Anthony B. Cavender, PillsburyMr. Cavender may be contacted at
anthony.cavender@pillsburylaw.com
