Seattle Washington Building Expert Directory

CGL Coverage for Liquidated Damages and the Contractual Liability Exclusion

October 09, 2023 — Stu Richeson - The Dispute Resolver
Liquidated delay damages are common in construction contracts and are generally imposed when a contractor fails to achieve substantial completion within the time required by the contract. While contracts like the AIA A201-2017 have provisions for extending the time to achieve substantial completion when delays are caused by circumstances beyond the contractor’s control, delays can result from factors other than improper management or planning and the like, for which the owner is not required to give the contractor additional time. Courts are split on whether there is ever coverage under a CGL policy for contractually agreed upon liquidated delay damages. Liquidated delay damages are often excluded under the contractual liability exclusion of most CGL policies. The contractual liability exclusion excludes coverage for “liability for which the Insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement.” Courts often find the contractual liability exclusion in a CGL policy precludes coverage for liquidated delay damages, because such damages are contractual in nature and are triggered by the failure to bring the contract to substantial completion by a fixed deadline, regardless of the cause of the delay. However, some courts will look to the cause of the delay and find that there is coverage under a CGL policy for liquidated delay damages that are the result of property damage caused by an accident or occurrence. In Clark Const. Grp., Inc. v. Eagle Amalgamated Serv., Inc., 01-2478-DV, 2005 WL 2092998, at *1 (W.D. Tenn. Aug. 24, 2005) a general contractor entered a contract for the renovation of the convention center in Memphis. Part of the project included the demolition of a structure attached to the convention center. The demolition work was improperly performed by a subcontractor and resulted in damage to the convention center. Read the court decision
Read the full story...
Reprinted courtesy of Stu Richeson, Phelps
Mr. Richeson may be contacted at stuart.richeson@phelps.com

Gatluak Ramdiet Named to The National Black Lawyers’ “Top 40 Under 40” List

February 20, 2023 — Lewis Brisbois
New York, N.Y. (February 2, 2023) - New York Associate Gatluak Ramdiet was recently named to The National Black Lawyers (NBL) “Top 40 Under 40” list. The NBL “Top 40 Under 40” recognizes the most talented Black attorneys under the age of 40 who have an outstanding reputation among peers, the judiciary, and the public. The honorees on this list are nominated from leading lawyers, current members, and Executive Committee members. Mr. Ramdiet is a member of Lewis Brisbois' Medical Malpractice, Healthcare, Life Sciences, General Liability, Construction, and Toxic Tort & Environmental Litigation Practices. He represents individual and institutional clients in complex and high exposure claims, with particular experience handling matters involving catastrophic injuries and serious medical conditions. As part of the New York Medical Malpractice team, he regularly represents individual healthcare providers, including physicians, physician assistants, and nurse practitioners. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

California Supreme Court Finds that When it Comes to Intentional Interference Claims, Public Works Projects are Just Different, Special Even

November 21, 2017 — Garret Murai - California Construction Law Blog
Originally published by CDJ on April 20, 2017 Earlier, we reported on a California Court of Appeals decision – Roy Allan Slurry Seal, Inc. v. American Asphalt South, Inc. – which held for the first time that a second-place bidder on a public works contract could sue a winning bidder who failed to pay its workers prevailing wages, under the business tort of intentional interference with prospective economic advantage. Fast forward nearly two years, several amicus briefs, and “one doghouse”* later and the California Supreme Court has . . . reversed. The Roy Allan Slurry Seal Case To catch you up, or rather, refresh your recollection . . . Between 2009 and 2012, American Asphalt South, Inc. was awarded 23 public works contracts totaling more than $14.6 million throughout Los Angeles, Orange, San Bernardino and San Diego counties. Two of the losing bidders on those projects – Roy Allan Slurry Seal, Inc. and Doug Martin Contracting, Inc. – sued American in each of these counties for intentional interference with prospective economic advantage as well as under the Unfair Practices Act (“UPA”) (Bus. & Prof. Code §§ 17000 et seq.) and the Unfair Competition Law (“UCL”) (Bus. & Prof. Code §17200). Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Insurer Motion to Intervene in Underlying Case Denied

August 10, 2021 — Tred R. Eyerly - Insurance Law Hawaii
The Colorado Supreme Court determined that the insurer defending under a reservation of rights could not intervene in the underlying case after the insured assigned its rights to any bad faith claim against the insurer. Auto-Owners Ins. Co. v. Bolt Factory Lofts Owners Ass'n, Inc., 2021 Colo. LEXIS 365 (Colo. May 24, 2021). Bolt Factory initiated a construction defects lawsuit against various contractors. Several defendants filed third-party complaints against subcontractors, including Sierra Glass Company. Auto-Owners agreed to defend its insured, Sierra Glass, under a reservation of rights. Auto-Owners declined to settle with Bolt Factory for $1.9 million, within policy limits. Sierra Glass then retains independent counsel and entered into a settlement with Bolt Factory. The settlement allowed Sierra Glass to assign its bad faith claims to Bolt Factory in exchange for the right to pursue the insurer for payment of the excess judgment rather than Sierra Glass. Instead of entering into a stipulated judgment, Bolt Factory and Sierra Glass proceeded to an abbreviated trial. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Administration Seeks To Build New FBI HQ on Current D.C. Site

February 28, 2018 — Tom Ichniowski – ENR
A Senate committee plans to examine a new $3.3-billion Trump administration proposal to demolish the Federal Bureau of Investigation's worn, outmoded headquarters in downtown Washington, D.C., and construct a new facility on that site. Read the court decision
Read the full story...
Reprinted courtesy of Tom Ichniowski, Engineering News-Record
Mr. Ichniowski may be contacted at ichniowskit@enr.com

Construction Defect Bill Removed from Committee Calendar

February 12, 2013 — CDJ STAFF
Colorado State Senator Mark Scheffel has removed Senate Bill 13-052 from the Senate Judiciary Committee’s calendar because he feels an upcoming study on construction near transit centers will be important for the consideration of the bill. SB 13-052 would affect construction defect claims in communities that were within a half mile of public transportation. Critics claim it would gut construction defect protections, as even a bus stop would count as a “mass transit center.” Scheffel says he doesn’t know what the study will find, but says that whether he likes or hates it, it will be relevant. Read the court decision
Read the full story...
Reprinted courtesy of

Appraisal Appropriate Despite Pending Coverage Issues

August 16, 2021 — Tred R. Eyerly - Insurance Law Hawaii
The court granted the insured's motion for partial summary judgment, allowing an appraisal to go forward even with outstanding coverage issues in dispute. DC Plastic Products Corp. v. Westchester Surplus Lines Ins. Co., 2021 U,.S. Dist. LEXIS 95908 (D. N.J. May 19, 2021). DC Plastic's property was damaged by Superstorm Sandy in October 2012. Claims submitted to Westchester resulted in a payment of $951,102.89 to DC Plastic. The parties disagreed on whether further payments were due. In 2017, DC Plastic sued Westchester for additional payments. DC Plastic moved to compel an appraisal for its claims, requesting that the court appoint an umpire for the appraisal process. Westchester cross-moved to dismiss the case in its entirety. DC Plastic's complaint asked that the court appoint an umpire. The policy stated if the parties could not agree on the amount of loss, each party would select an appraiser, who would then agree upon an umpire. If they could not agree, either party could request the court to appoint the umpire. Therefore, the court was authorised to select the umpire here. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Chinese Billionaire Sues Local Governments Over Project Payment

January 28, 2015 — Bloomberg News
The billionaire founder of closely held China Pacific Construction Group sued six local governments in a bid to force payment of 900 million yuan ($144 million) his company is owed for infrastructure projects. Yan Jiehe said today he was trying to prove a point and winning the lawsuits wasn’t his main goal. Courts in Hebei, Yunnan, Guizhou, Hunan and Shandong provinces accepted the cases, he said in an interview. “We cannot let the governments work without any supervision anymore,” Yan said. “The results of the lawsuits are not that important to me and I care more about rule of law.” Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg News

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES