Tarriffs, a Pandemic and War: Construction Contracts Must Withstand the Unforeseeable
May 16, 2022 —
Brett Moritz, Adrian Bastianelli III & Adam Handfinger - Construction ExecutiveSince the tariffs on steel and the first wave of the COVID-19 pandemic, the construction industry has been reeling from the impact of material shortages and price increases, labor shortages, breakdowns in the supply chain and the inflationary effect of these issues. Unfortunately, the war in Ukraine has only exacerbated the situation.
International conflicts can constrain supply, resulting in delays and price increases for contractors, subcontractors and suppliers. The disruption caused by the war is expected to be particularly acute due to the role that Russia and Ukraine play in the world economy and the effect of the economic sanctions that have been imposed on Russia by the United States and other countries. Russia controls approximately 10% of the global copper reserves and is estimated to produce about 10% of the world’s nickel supply. It also provides at least 30% of Europe’s oil and natural gas. Ukraine is a significant source of raw materials, such as iron. Thus, the war will cause significant shortages and price increases to the global construction industry. There are already reports of delays and cost increases for commodities such as nickel, aluminum, copper and—most importantly—steel, which have resulted in impacts to construction costs and schedules. Suppliers are especially sensitive to the volatile markets caused by these conditions. Some are insisting on automatic price increases in their purchase orders.
All of this, not to mention the anticipation of what may come next, points to the necessity for a new paradigm to achieve a successful project. It is more important today than ever that owners, contractors, subcontractors and suppliers reasonably address the economic and time impacts of these unforeseeable events in preparing contracts for future work and in administering existing contracts. Otherwise, the risk of a default on more than one level may put projects in jeopardy, to no one’s benefit.
Reprinted courtesy of
Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Construction Law Alert: Unlicensed Contractors On Federal Projects Entitled To Payment Under The Miller Act
May 07, 2014 —
Steven M. Cvitanovic and Jessica M. Lassere Ryland - Haight Brown & Bonesteel, LLPAs a matter of first impression, the Ninth Circuit Court of Appeals in Technica LLC ex rel. U.S. v. Carolina Cas. Ins. Co., 12-56539, 2014 WL 1674108 (9th Cir. Apr. 29, 2014), allowed an unlicensed subcontractor to recover from a prime contractor for unpaid services relating to a federal construction project under a federal Miller Act claim. California law otherwise prevents unlicensed contractors from recovering for unpaid work on non-federal projects as a penal measure intended to encourage contractors to maintain a valid license at all times.
Technica LLC (“Technica”) worked as a sub-subcontractor on a large federal fence replacement project (the “Project”). Over the course of a year, Technica supplied nearly a million dollars worth of labor, materials, and services for the Project. However, Technica received only $287,861.81 in partial payments for its work. Technica proceeded to file suit in district court against the prime contractor Candelaria Corporation (“Candelaria”) and its payment surety Carolina Casualty Insurance Company (“CCIC”) under the Miller Act to recover amounts owed to it on the subcontract against the payment bond.
Reprinted courtesy of
Steven M. Cvitanovic, Haight Brown & Bonesteel, LLP and
Jessica M. Lassere Ryland, Haight Brown & Bonesteel, LLP
Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com; Ms. Lassere Ryland may be contacted at jlassere@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Real Estate & Construction News Round-Up (02/08/23) – The Build America, Buy America Act, ESG Feasibility, and University Partnerships
February 27, 2023 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogThis week’s round-up explores President Joe Biden’s recent State of the Union address and plans for the Build America, Buy America Act, the feasibility of real estate companies achieving their ESG goals, and how developers, lenders, and tenants are partnering with universities to solve real estate challenges.
- During his annual State of the Union address, President Joe Biden detailed his Build America, Buy America plans and standard to require all construction materials on federal infrastructure projects to be made in the United States. (Jennifer Goodman & Zachary Phillips, Construction Dive)
- Speculation surrounding the economic environment and real estate stability is testing the feasibility and resilience of the environmental, social and corporate governance (ESG) framework used by corporations to measure their societal impact. (Anna Staropoli, Commercial Observer)
- Adopting Web3 and decentralization in the real estate industry is projected to bring about significant changes and improvements. (David Bitton, Forbes)
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Despite Construction Gains, Cement Maker Sees Loss
May 10, 2013 —
CDJ STAFFVulcan Materials, the Birmingham, Alabama-based business that describes itself as the nation’s largest producer of construction aggregates and aggregate-based construction materials, has reported that its losses have increased to $54.8 million in the first quarter of 2013. This was on revenues of $538 million, an increase from the past. The first quarter also saw the company shipping 248,000 tons of material, an increase of fourteen percent over the first quarter of 2012. Losses were attributed to bad weather, lower production volumes, and an increase in costs.
Global Cement quotes Don James, the chairman and CEO of Vulcan, “growth in residential construction activity and its traditional follow-on impact to private non-residential construction underpins our expectations for volume and earnings improvement in 2013.”
Read the court decisionRead the full story...Reprinted courtesy of
Avoid a Derailed Settlement in Construction
March 28, 2022 —
Patrick Barthet - Construction ExecutiveMore and more construction cases are settling because lawyers know juries can prove to be unpredictable. The litigation process, as well as any actual trial, can be stressful, expensive and quite lengthy. Settlements are, for the most part, private while suits are public. Current reports find more than 90% of civil cases filed in state circuit courts are disposed of before trial. When that doesn't happen, things could go very poorly, as the case below illustrates.
The Case
Adam was seriously injured in a collision with a dump truck owned by Bang and driven by Tomas. While suit by Adam against Bang and Tomas was pending, Adam suggested they settle by having Bang pay him. Upon receipt of the offer, Bang's lawyer reached out confirming that his client was okay with the settlement amount but wished to add that the settlement also include the satisfaction of a lien filed by Adam's workers' compensation carrier. Adam's attorney refused that additional request, but that didn't stop Bang's lawyer. Based on the fact that Adam had agreed to the settlement amount, the lawyer filed a boiler plate notice of acceptance of settlement and had Bang issue a settlement check payable to Adam in the amount Adam had requested. Adam remained unwilling to compromise. He continued to resist the modified terms, which added satisfaction of the worker’s compensation lien. Bang then filed a motion to enforce settlement, arguing that since there was agreement on the settlement amount, Adam was required to do the deal.
Reprinted courtesy of
Patrick Barthet, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Barthet may be contacted at
pbarthet@barthet.com
No Conflict in Successive Representation of a Closely-Held Company and Its Insiders Where Insiders Already Possess Company’s Confidential Information
August 02, 2017 —
Renata L. Hoddinott, David W. Evans, & Howard M. Garfield - Haight Brown & Bonesteel LLPIn Beachcomber Management Crystal Cove, LLC v. Superior Court (Salisbury) (No. G054078, filed June 28, 2017; pub. and mod. order July 28, 2017), the Fourth Appellate District granted a writ of mandate vacating a trial court’s order disqualifying defendants’ counsel.
In Beachcomber, plaintiffs filed a shareholder derivative action against defendants Beachcomber Management and Douglas Cavanaugh (collectively, “defendants”) alleging defendants abused their position and mismanaged nominal defendant and similarly named Beachcomber at Crystal Cove (“Beachcomber”). Between 2009 and 2011, defendants and Beachcomber had each hired Kohut & Kohut LLP (“Kohut”) to represent them on at least four different occasions. In the underlying action, defendants hired Kohut again to represent them, while Beachcomber hired another law firm to represent it.
Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys
Renata L. Hoddinott,
David W. Evans and
Howard M. Garfield Read the court decisionRead the full story...Reprinted courtesy of
Canada's Ex-Attorney General Set to Testify About SNC-Lavalin Scandal
April 03, 2019 —
Associated Press - Engineering News-RecordTORONTO (AP) — Canada's former attorney general is expected to testify Wednesday about whether she was inappropriately pressured by Prime Minister Justin Trudeau's office to avoid prosecuting a major Canadian engineering company.
Ex-Attorney General Jody Wilson-Raybould has said she wants to tell "her truth" and she will speak at a hearing of the Parliament justice committee.
Read the court decisionRead the full story...Reprinted courtesy of
Engineering News-RecordENR may be contacted at
ENR.com@bnpmedia.com
Concurrent Causation Doctrine Applies Where Natural and Man-made Perils Combine to Create Loss
January 19, 2017 —
Tred R. Eyerly – Insurance Law HawaiiThe Florida Supreme Court resolved a conflict between the District Courts in applying the Concurrent Causation Doctrine where there were multiple causes creating the loss. Sebo v. Am. Home Assur. Co., 2016 Fla. LEXIS 2596 (Fla. Dec. 1, 2016).
After purchasing his home, John Sebo procured an "all risks" homeowners policy provided by American Home Assurance Company (AHAC). Shortly after Sebo purchased the property, water began to intrude the home during rainstorms. Major water leaks occurred. It became clear that the home suffered from major design and construction defects. In October 2005, Hurricane Wilma further damaged the home.
AHAC denied coverage for most of the claimed losses. It provided $50,000 for mold. The residence could not be repaired and was eventually demolished.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com